Timing of the Project Sample Clauses

Timing of the Project. The parties agree to use their best efforts to meet the deadlines included in this Agreement, but acknowledge that weather and acts of outside regulatory entities, including utilities, may delay the completion of the acts described herein. In the event of such delays, the parties agree to negotiate in good faith to reasonably extend said deadlines. Deleted: 9.
AutoNDA by SimpleDocs
Timing of the Project. The Applicant shall undertake all reasonable efforts to proceed diligently and in a timely manner with the Project, including:
Timing of the Project. Construction of the Project Improvements shall commence as within thirty (30) days from the date of the receipt of all non-appealable Approvals, but in no event shall construction occur prior to the execution of the Financial Agreement described in Paragraph 4 below. The Project Improvements shall be completed within twenty-four (24) months from the date upon which this Agreement is fully executed. The time for commencement and completion can be extended for a period of time equal to any delay in construction due to any of the causes set forth in Paragraph 11 hereof or as a result of any pending or threatened administrative procedures or litigation which will interfere with the Redeveloper’s ability to commence or complete the Project Improvements. The parties can extend the time to complete the Project Improvements based on mutual written agreement.
Timing of the Project. (a) As soon as practicable following the execution and delivery of this Agreement by the parties,
Timing of the Project. The States agree that the Project should be implemented expeditiously. It is recognised that there are distinct technical advantages in having the Initial Dredging take place concurrently with the commissioning of the sand bypassing system. However, it is accepted that there are broader advantages in carrying out the Initial Dredging as soon as possible and as a compromise the Initial Dredging should be undertaken at the earliest possible date and the interval between the Initial Dredging and the commissioning of the bypass should be the minimum possible. (It is envisaged that contracts will be let for the Initial Dredging in late 1994 and that the bypass will be operational by 1996).
Timing of the Project. TDL is prepared to undertake the design and installation upon receipt of this signed proposal. One month is required to obtain approval from NS Power for this project. TDL estimates that two months will be required to acquire all the system hardware, and another month is required to install the system and commission it. System Price PV modules $107,520 Inverters $36,000 Balance of system $51,610 Direct labour $49,459 Building permits $150 Electrical inspections/permits $1,000 Overhead costs $10,752 includes administration Total installation costs $256,491 plus applicable taxes Thermo Dynamics Ltd. proposes to design, supply and install the above system. The cost of the TDL-supplied system is $256,491.00 (two hundred and fifty-six thousand, four hundred and ninety-one dollars), plus applicable taxes. Cost of connection to the NS Power grid TDL provided a cost estimate for the equipment that NS Power will require between the solar PV electrical panel and the NS Power distribution system. This estimated interconnection equipment cost is not part of the total contract price. TDL shall procure the equipment specified by NS Power for installation between the solar PV electrical panel and the NS Power distribution system, and invoice these costs (the interconnection costs) with receipts and without markup to TOA, upon achieving commercial operation for the project. TDL’s installation costs of such equipment is included in the direct labour costs shown above. Payment Schedule TOA shall pay to TDL the total contract price plus the interconnection costs shown above upon receipt of an invoice from TDL on the following schedule:

Related to Timing of the Project

  • Development of the Project 4.1 TSP's obligations in development of the Project: Subject to the terms and conditions of this Agreement, the TSP at its own cost and expense shall observe, comply with, perform, undertake and be responsible:

  • Completion of the Project The Contracting Party shall complete the construction, equipping and furnishing of the Improvements in accordance with the Plans and submit to the Board a Certificate of Completion on or before November 1, 2016.

  • Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.

  • Operation of the Property During the Term, NAI shall operate the Property in a good and workmanlike manner and substantially in compliance with all Applicable Laws and will pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written notice given to NAI or BNPLC by any governmental authority, then for purposes of the preceding sentence, NAI shall be considered not to have maintained the Property "substantially in accordance with Applicable Laws" whether or not the noncompliance would be substantial in the absence of the notice.) During the Term, NAI shall not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. During the Term, to the extent that any of the following would, individually or in the aggregate, materially and adversely affect the value of the Property or NAI's use, occupancy or operations on the Property, NAI shall not, without BNPLC's prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. If (A) a change in the zoning or other Applicable Laws affecting the permitted use or development of the Property shall occur after the Base Rent Commencement Date that reduces the value of the Property, or (B) conditions or circumstances on or about the Property are discovered after the Base Rent Commencement Date (such as the presence of an endangered species) which substantially impede development and thereby reduce the value of the Property, and if after any such reduction under clause (A) or (B) preceding the Current AS IS Market Value of the Property is less than sixty percent (60%) of Stipulated Loss Value, then NAI shall pay BNPLC upon request the amount by which Current AS IS Market Value is less than sixty percent (60%) of Stipulated Loss Value, for application as a Qualified Prepayment. During the Term, NAI shall not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI shall not do any act whereby the market value of the Property may reasonably be expected to be materially lessened. During the Term, if NAI receives a written notice or claim from any federal, state or other governmental entity that the Property is not in compliance in any material respect with any Applicable Law, or that any action may be taken against the owner of the Property because the Property does not comply with Applicable Law, NAI shall promptly furnish a copy of such notice or claim to BNPLC. Notwithstanding the foregoing, NAI may in good faith, by appropriate proceedings, contest the validity and applicability of any Applicable Law with respect to the Property, and pending such contest NAI shall not be deemed in default hereunder because of the violation of such Applicable Law, if NAI diligently prosecutes such contest to completion in a manner reasonably satisfactory to BNPLC, and if NAI promptly causes the Property to comply with any such Applicable Law upon a final determination by a court of competent jurisdiction that the same is valid and applicable to the Property; provided, however, in any event such contest shall be concluded and the violation of such Applicable Law must be corrected by NAI and any claims asserted against BNPLC or the Property because of such violation must be paid by NAI, all prior to the earlier of (i) the date that any criminal prosecution is instituted or overtly threatened against BNPLC or any of its directors, officers or employees because of such violation, (ii) the date that any action is taken by any governmental authority against BNPLC or any property owned by BNPLC (including the Property) because of such violation, or (iii) a Designated Sale Date upon which, for any reason, NAI or an Affiliate of NAI or any Applicable Purchaser shall not purchase BNPLC's interest in the Property pursuant to the Purchase Agreement for a price to BNPLC (when taken together with any additional payments made by NAI pursuant to Paragraph 1(A)(2) of the Purchase Agreement, in the case of a purchase by an Applicable Purchaser) equal to the Break Even Price.

  • Maintenance of the Property Neither Broker nor Brokerage Firm is responsible for maintenance of the 324 Property nor are they liable for damage of any kind occurring to the Property, unless such damage is caused by their negligence or 325 intentional misconduct.

  • The Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part.

  • Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.

  • Use of the Property The Tenant agrees with the Landlord as follows:-

  • Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:

  • Project Completion Part 1 – Material Completion

Time is Money Join Law Insider Premium to draft better contracts faster.