Construction Act. Construction Act means the Construction Act, RSO 1990, c. C 30.
Construction Act. The Owner covenants and agrees that it will hold back in its payments to any contractor who may construct services, facilities or works, such amounts as may be required under the provisions of the Construction Act, R.S.O. 1990, c. C.30, as amended.
Construction Act. 52. The Purchaser covenants and agrees that he is a “home buyer” within the meaning of the Construction Act of Ontario, as may be amended, and will not claim any lien holdback on the Closing Date.
Construction Act. 13. The Purchaser covenants and agrees that he/she is a “home buyer” within the meaning of the Construction Act, R.S.O. 1990, c.C.30. and will not claim any lien holdback on the Occupancy Date or Title Transfer Date. The Vendor shall complete the remainder of the Condominium according to its schedule of completion and neither the Occupancy Date nor the Title Transfer Date shall be delayed on that account. The Planning Act
Construction Act. Upon receiving notice or upon any liens being filed pursuant to the Construction Act which may affect any portion of the subject Lands in this Agreement in which the Town may have an interest, this Agreement shall be deemed to be defaulted by the Owner. Upon discovering such default, the Town may forthwith give the Owner notice in writing of the said lien or claim and the Owner shall be allowed to cure or remedy such default by discharging or vacating the said lien to the satisfaction of the Town within ten (10) days of such notice. If such default is not remedied or cured as above, the Town may, notwithstanding any other remedies it may have, draw upon any security or Letter of Credit which may be held pursuant to this Agreement to secure its interests and may pay into Court any holdback and costs provided by the Construction Act as may be necessary therefor. The Owner shall provide a statutory declaration that it has paid all contractors, sub-contractors and consultants associated with the construction of public works and complied fully with the provisions of the Construction Act.
Construction Act. The Contractor shall give the Owner notice in writing, immediately, of all lien claims or potential lien claims coming to the knowledge of the Contractor or his agents. When a claim for lien is filed by a Subcontractor, labour or material supplier or equipment renter acting under the Contractor, and proceedings are commenced by the Owner to vacate the lien, the Contractor agrees and shall forthwith pay to the Owner, in addition to their reasonable legal fees therefore, all interest costs and expenses incurred by the Owner and an additional sum equal to ten percent (10%) of the sum found to be owing as liquidated damages, and such remedy shall be in addition to any other remedy available to the Owner under the Contract Documents. Where any lien claimant asks from the Owner the production for inspection of the Contract Documents or the state of the accounts between the Owner and the Contractor, the Contractor shall be liable for an administration fee of Two Hundred Dollars ($200.00) for each request made as compensation for the preparation of such accounting or for the preparation of the Contract, or both, as the case may be, and the Contractor acknowledges that such administrative fee shall be properly deductible, if the Owner should so choose, from monies otherwise payable to the Contractor under the terms of the Contract Documents. Where an application is brought to a judge of a competent jurisdiction to compel production of any particular document to a lien claimant, the Contractor further agrees to indemnify the Owner from reasonable legal fees incurred in appearing on such an application and in addition agrees to pay to the Owner its reasonable costs incurred in producing such documents to the extent that the same is made necessary under the disposition of the matter by such judge, and the Contractor further agrees that such reasonable costs and fees incurred by the Owner as stated herein may be properly deductible from monies otherwise payable to the Contractor under the terms of the Contract Documents.
Construction Act. Upon receiving notice or upon any liens being filed with the Town pursuant to the Construction Act, R.S.O. 1990, c.C.30, as amended, on the Lands in this Agreement in which the Town may have an interest, this Agreement shall be deemed to be defaulted by the Owner. Upon discovering such default, and the Owner fails to discharge the lien or the claim as the case may be within ten (10) business days after receipt of notice from the Town, then the Town may, notwithstanding any other remedies it may have, draw the full amount of the claim from any security or Letter of Credit which may be held pursuant to this Agreement to secure its interests and may pay into Court any holdback and costs provided by the Construction Act as may be necessary therefore. The Owners agree to submit a Statutory Declaration that it has paid all contractors and sub-contractors associated with the construction of public works and complied fully with the provisions of the Construction Act.
Construction Act. (a) Project Co shall comply with the holdback requirements under the Construction Act.
Construction Act. 4.34.1 The Construction Act applies to all aspects of the performance of this Contract. A copy of any claim for lien under the Construction Lien Act, and applicable affidavit verifying same, must be provided to: The Ontario Aggregate Resources Corporation 0000 Xxxxxxxxx Xxx., Xxxxx 000 Xxxxxxxxxx, XX L7L 5Z4
Construction Act. 50. The Developer shall pay promptly those employed in the construction, installation, maintenance and repair of the Site Development Works, but shall hold back such sums as are required to be held back by the Construction Act and the Developer shall indemnify the Municipality against any losses, claims, actions or demands for Construction Liens or otherwise in connection with the Site Development Works; and, on demand by the Municipality, the Developer shall forthwith discharge any such lien or any certificate of action which may be registered against either or both of the Site Development Works or the Land.
