LANDLORD'S REMEDIES definition

LANDLORD'S REMEDIES. Any failure to pay rent as provided, vacating of the premises prior to the expiration of the term, or breach of any other covenant of this lease by Tenant shall entitle Landlord, without obligation to do so, and in addition to other rights or remedies it may have, to declare this lease terminated and the term ended and/or to the immediate right of re-entry. Should Landlord elect to re-enter the premises, it may either terminate this lease or it may from time to time, without terminating this lease, relet said premises, and the Tenant agrees to be liable for the balance of the rent until the expiration of this lease. Upon each such reletting, all rentals and other sums received by Landlord from such reletting shall be applied, first to the payment of debt other than rent due Landlord; second, to costs and expenses of reletting; and third, to past-due rent; and the residue, if any, shall be held by Landlord and applied in payment of future rent as the same may become due and payable hereunder. No such re-entry or taking possession of said premises by Landlord shall be construed as election on its part to terminate this lease unless a written notice of such intention be given to Tenant or unless the termination thereof be decreed by a court of competent jurisdiction. Tenant agrees that if enforcement of the terms of this lease by Landlord is necessary, Tenant shall be responsible for Landlord's reasonable attorney's fees. LANDLORD: TENANT: XXXXXX PROPERTY MANAGEMENT XXXXXX.XXX D/B/A EXECUTIVE SUITES AND 0000 XXXXXXXX BUSINESS SERVICES, LLC XXXXX 0000 0000 XXXXXXXX, XXXXX 0000 XXXXXX, XXXXXXXX 00000 XXXXXX, XXXXXXXX 00000 BY:/s/ Xxx X. Xxxxxxx BY: /s/ Xxx Xxxxxxxx ------------------- ------------------ Xxx X. Xxxxxxx Xxx Xxxxxxxx
LANDLORD'S REMEDIES. 9. All amounts payable by Tenant to Landlord hereunder shall be deemed to be Rent under the Lease and upon any default in the payment of same, Landlord shall have all of the rights and remedies provided for in the Lease. TENANT: LANDLORD: LODESTAR FINANCIAL SERVICES, INC. 000 XXXXX XXXXXXX ASSOCIATES, L.P., an Illinois limited partnership By: /s/ Xxxxxxx X. Xxxxxxxxx By: /s/ Xxxxxx X. Xxxxxxxx ----------------------------- -------------------------- Title: President Title: Managing Member -------------------------- ----------------------- EXHIBIT "E" LODESTAR FINANCIAL SERVICES, INC. BUILDING STANDARDS BUILDING COMPONENTS

Examples of LANDLORD'S REMEDIES in a sentence

  • Xxxxxx Its: Vice President Attention: Xxxxxx Xxxxxx, CFO 00-00 Xxxxxxxx Xxxxxx Needham, MA 02192 Telephone: ( ) Telephone: ( ) Facsimile: ( ) Facsimile: ( ) Executed at: Executed at: LANDLORD'S REMEDIES IN EVENT OF TENANT DEFAULT ADDENDUM This Remedies Addendum is part of the Lease dated ______________________ by and between KEEP YOUR DAY JOB LLC and XXXXXXXXXXX.XXX for the premises known as 000 Xxxxxxxx Xxxxxx, Xxxxxxxxx, XX.

  • LANDLORD'S REMEDIES ON DEFAULT:...........................................5 11.

  • DEFAULT PROVISIONS, LANDLORD'S REMEDIES........................................................

  • ACCEPTANCE OF SUCH PAYMENT SHALL NOT BE CONSTRUED AS A CONSENT BY LANDLORD TO TENANT'S SUCH USE, OR LIMIT LANDLORD'S REMEDIES UNDER THIS LEASE.

  • LANDLORD'S REMEDIES FOR TENANT'S DEFAULT.....................................................-18- 26.

  • LANDLORD'S REMEDIES FOR TENANT'S DEFAULT........................................................

  • LANDLORD'S REMEDIES FOR TENANT'S DEFAULT.......................164 25.

  • TENANT'S DEFAULT AND LANDLORD'S REMEDIES.............................

  • LANDLORD'S REMEDIES UPON DEFAULT........................................................................12 22.

  • LANDLORD'S REMEDIES: LANDLORD shall have the following remedies if TENANT commits a default.

Related to LANDLORD'S REMEDIES

  • Landlord Default shall have the meaning given such term in Article 14.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Landlord shall have the meaning given such term in the preambles to this Agreement and shall also include their respective permitted successors and assigns.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition, Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 12 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Additional Rents means amounts payable under any Lease for (i) the payment of additional rent based upon a percentage of the Tenant’s business during a specified annual or other period (sometimes referred to as “percentage rent”), (ii) so-called common area maintenance or “CAM” charges, and (iii) so called “escalation rent” or additional rent based upon such tenant’s allocable share of insurance, real estate taxes or operating expenses or labor costs or cost of living or xxxxxx’x wages or otherwise.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Additional Rent means all amounts payable by the Tenant under this Lease except Base Rent, whether or not specifically designated as Additional Rent elsewhere in this Lease;

  • Tenant’s Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.

  • Tenants means the tenants under the Leases.

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Master Lease means any master lease now or hereafter entered into, in which the Healthcare Facility is aggregated with other HUD-insured healthcare facilities and leased to a Master Tenant and any amendments or joinders thereto.

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.

  • Lessor means a person who transfers the right to possession and use of goods under a lease. Unless the context clearly indicates otherwise, the term includes a sublessor.

  • Landlord Personal Property Collateral Access Agreement means a Landlord Waiver and Consent Agreement substantially in the form of Exhibit L, with such amendments, modifications or supplements thereto as may be approved by the Administrative Agent.