Tenant’s Entry Into the Premises Prior to Substantial Completion Subject to the terms hereof and provided that Tenant and its agents do not interfere with, or delay, Contractor’s work in the Building and the Premises, at Landlord’s reasonable discretion, Contractor shall allow Tenant access to the Premises prior to the Substantial Completion of the Premises for the purpose of Tenant installing any necessary furniture, equipment or fixtures (including Tenant’s data and telephone equipment) in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 6.01, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry, and Landlord will reasonably cooperate with Tenant to coordinate Landlord’s Contractor’s work of constructing the Tenant Improvements with such access by Tenant for the installation of Tenant’s furniture, equipment and fixtures. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s Contractor, agents or representatives in performing work in the Building and the Premises, or interfere with the general operation of the Building and/or the Project; and such entry shall be subject to the site management rules of Landlord and Landlord’s Contractor. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Premises and against injury to any persons caused by Tenant’s actions pursuant to this Section 6.01.
Landlord’s Entry Landlord and its authorized representatives may at all reasonable times and upon reasonable notice to Tenant enter the Premises to: (a) inspect the Premises; (b) exercise and perform Landlord's rights and obligations under this Lease; (c) post notices of non-responsibility or other protective notices available under the Laws; (d) show the Premises to current or prospective mortgagees, or to prospective purchasers of the Property; or (e) during the last 12 months of the Term, show the Premises to prospective tenants. Landlord, in the event of any emergency, may enter the Premises at any time without notice to Tenant. If Landlord receives prior written notification from Tenant that specified areas within the Premises contain confidential materials, then Landlord shall not enter such portions of the Premises unless accompanied by a representative of Tenant except (i) in case of an emergency, or (ii) if Tenant authorizes Landlord to enter such portions of the Premises without accompaniment of Tenant's representative. Landlord's entry into the Premises is not to be construed as a forcible or unlawful entry into, or detainer of, the Premises or as an eviction of Tenant from all or any part of the Premises. Subject to Section 9.3 below, Tenant will also permit Landlord (or its designees) to erect, install, use, maintain, replace and repair pipes, cables, conduits, plumbing and vents, and telephone, electric and other wires or other items, in, to and through the Premises if Landlord reasonably determines that such activities are necessary for properly operating and maintaining the Building.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” and “Force Majeure Delays” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect; provided, however, that if Landlord does not Deliver the Premises within 150 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, in which case subsections (a) and (b) of this paragraph shall apply. If Tenant does not elected to void this Lease within 10 business days of the lapse of such 150 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.
Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant subleases and rents from Sublandlord, the Premises (the “Subleased Premises”).
Leased Premises Lessor hereby leases to Lessee, and Lessee leases and takes from Lessor, the Leased Premises subject to the conditions of this Lease.
The Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto, and an outline of the Project is set forth in Exhibit A-1 attached hereto. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease, Tenant shall accept the Premises in its presently existing “as-is” condition and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant’s business, except as specifically set forth in this Lease. However, notwithstanding the foregoing, Landlord agrees that base Building electrical, mechanical, heating, ventilation and air conditioning and plumbing systems located in the Premises shall be in good working order and the roof shall be water tight as of the date Landlord delivers possession of the Premises to Tenant. Except to the extent caused by the acts or omissions of Tenant or any Tenant Parties (as defined in Section 10.13 below) by any alterations or improvements performed by or on behalf of Tenant, if such systems and/or the roof are not in good working order as of the date possession of the Premises is delivered to Tenant and Tenant provides Landlord with notice of the same within ninety (90) days following the date Landlord delivers possession of the Premises to Tenant, Landlord shall be responsible for repairing or restoring the same at Landlord’s sole cost and expense. Subject to any repairs or restoration required by the immediately preceding sentence, the commencement of business operations from the Premises by Tenant shall presumptively establish that the Premises and the Building were at such time in good and sanitary order, condition and repair. For purposes of Section 1938 of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges, that the Premises, the Building and the Project have not undergone inspection by a Certified Access Specialist (CASp).
Sublease Term The term of the Sublease (“Sublease Term”) commences on the later to occur of (1) Sublandlord’s receipt of Prime Landlord’s written consent to this Sublease, and (2) October 1, 2009 (“Sublease Commencement Date”); and expires on January 28, 2018 (“Sublease Expiration Date”; i.e., the day prior to the Termination Date pursuant to the Prime Lease). Sublandlord shall deliver the Subleased Premises “broom clean” and free of all of Sublandlord’s personal property (other than the F&F (defined in Section 2(f))) and debris, but otherwise in “AS IS, WHERE IS” condition on the Sublease Commencement Date; provided that Subtenant shall not be responsible for, or required to remedy, any violation of any applicable law, or any condition or state of facts, with respect to the Subleased Premises, the Building or the Land existing on or prior to the Sublease Commencement Date. Sublandlord is not required to perform any work to prepare the Subleased Premises for Subtenant’s intended use. If (i) for any reason Sublandlord has not received Prime Landlord’s written consent to this Sublease in form required by Section 15(i) below by the date which is sixty (60) days from the date hereof, or (ii) Prime Landlord elects to terminate the Prime Lease in respect of the Subleased Premises pursuant to Prime Landlord’s recapture right set forth in Section 16.5 of the Prime Lease, then in the case of (i), then Sublandlord and Subtenant each may elect at any time thereafter to terminate this Sublease by written notice to the other, whereupon the parties shall deem this Sublease to be null and void and of no effect (except for those provisions expressly stated herein to survive a termination), and in the case of (ii) the Sublease will be deemed terminated in accordance with Section 16.5 of the Prime Lease.
