No Abatement of Rent This Agreement shall remain in full force and effect and Tenant’s obligation to make all payments of Rent and to pay all other charges as and when required under this Agreement shall remain unabated during the Term notwithstanding any damage involving the Leased Property, or any portion thereof (provided that Landlord shall credit against such payments any amounts paid to Landlord as a consequence of such damage under any business interruption insurance obtained by Tenant hereunder). The provisions of this Article 10 shall be considered an express agreement governing any cause of damage or destruction to the Leased Property, or any portion thereof, and, to the maximum extent permitted by law, no local or State statute, laws, rules, regulation or ordinance in effect during the Term which provide for such a contingency shall have any application in such case.
Base Rent Abatement Provided that Tenant is not then in Default, and subject to the terms of this Section 3.2 below, then (i) during the last six (6) full calendar months of the Lease Term with respect to the Phase I Premises and (ii) during the last ten (10) full calendar months of the Lease Term with respect to the Phase II Premises (collectively, the “Base Rent Abatement Period”), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the Premises or the Phase II Premises, as applicable, during such Base Rent Abatement Period (collectively, the “Rent Abatement Amount”). Tenant acknowledges and agrees that the foregoing Base Rent Abatement has been granted to Tenant as additional consideration for entering into this Lease, and for agreeing to pay the rental and perform the terms and conditions otherwise required under this Lease. Notwithstanding the foregoing, Landlord shall have the right, at Landlord’s option, on a month by month basis commencing on the Lease Commencement Date, to accelerate any remaining Base Rent Abatement Amount relating to a full month during the Base Rent Abatement Period for a particular phase of the Premises (the “Phase”) forward, to apply to the Base Rent that would otherwise be due with respect to the next occurring month of the Lease Term for such Phase (the “Landlord Base Rent Abatement Acceleration Election”), in which case Tenant shall have no obligation to pay Base Rent attributable to such next occurring month of the Lease Term for such Phase, and the Base Rent Abatement Amount that is accelerated forward shall no longer be applicable during the Base Rent Abatement Period. Landlord may make such election on a month by month basis with respect to each of the months of the Base Rent Abatement Period. In addition, commencing on the Lease Commencement Date, if Landlord has not exercised the Landlord Base Rent Abatement Acceleration Election on or before the date that the next installment of Base Rent is due under the Lease, and provided that the Lease has not been terminated as a result of any Default of Tenant or rejection of the Lease in bankruptcy (the “Abatement Condition”), then Tenant shall have the right, at Tenant’s option, on a month by month basis commencing on the Lease Commencement Date, to accelerate any Base Rent Abatement Amount relating to a full month during the Base Rent Abatement Period for a Phase forward to apply to the Base Rent that would otherwise be due with respect to the next occurring month of the Lease Term for such Phase (the “Tenant Base Rent Abatement Acceleration Election”), in which case Tenant shall have no obligation to pay Base Rent attributable in such next occurring month of the Lease Term for such Phase, and the Base Rent Abatement Amount that is accelerated forward shall no longer be applicable during the Base Rent Abatement Period. Tenant may not elect to accelerate more than one (1) month of such Base Rent Abatement at any particular time. Notwithstanding the foregoing, as long as the Abatement Condition is satisfied, if Tenant fails to deliver notice to Landlord exercising the Tenant Base Rent Abatement Acceleration Election for a particular month of the Lease Term, then Tenant shall be deemed to have elected to exercise the Tenant Base Rent Abatement Acceleration Election for such month without the requirement of providing notice to Landlord. Notwithstanding the different monetary amount of one (1) full calendar month at the end of the Lease Term from the monetary amount of one (1) full calendar month at the beginning of the Lease Term, the value of any full month of Base Rent Abatement, whether accelerated by Landlord or by Tenant, shall be equal to one (1) full month of Base Rent at the time it is applied.
Landlord Delay As used herein, (x) “Force Majeure Construction Delay” shall mean acts of God, casualties, natural disasters, strikes, war, terrorist attacks, lockouts, labor disputes or civil commotion, and (y) “Landlord Delay” shall mean a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Sublease Rent Limitation Anything contained in this Lease to the contrary notwithstanding, Lessee shall not sublet the Leased Property on any basis such that the rental to be paid by the sublessee thereunder would be based, in whole or in part, on either (a) the income or profits derived by the business activities of the sublessee, or (b) any other formula such that any portion of the Rent would fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Code, or any similar or successor provision thereto.
Non-Renewal Termination If the Agreement expires as set forth in Section 6(g) [Non-Renewal Termination], then, subject to Section 22 [Compliance with Section 409A], in addition to all salary, annual bonuses, expense reimbursements, benefits and accrued vacation days earned by the Executive pursuant to Section 4 through the date of the Executive’s termination of employment, the Executive shall be entitled to the compensation set forth in Sections 8(d)(i) through (v), provided that within sixty days following the Executive’s termination of employment (i) the Executive has executed and delivered the Release to the Company, and (ii) the Release has become irrevocable:
Lease Termination Except as provided in this Section 9.04, upon expiration or earlier termination of this Lease Tenant shall surrender the Premises to Landlord in the same condition as existed on the date Tenant first occupied the Premises, (whether pursuant to this Lease or an earlier lease), subject to reasonable wear and tear. All Alterations shall become a part of the Premises and shall become the property of Landlord upon the expiration or earlier termination of this Lease, unless Landlord shall, by written notice given to Tenant, require Tenant to remove some or all of Tenant’s Alterations, in which event Tenant shall promptly remove the designated Alterations and shall promptly repair any resulting damage, all at Tenant’s sole expense. All business and trade fixtures, machinery and equipment, furniture, movable partitions and items of personal property owned by Tenant or installed by Tenant at its expense in the Premises shall be and remain the property of Tenant; upon the expiration or earlier termination of this Lease, Tenant shall, at its sole expense, remove all such items and repair any damage to the Premises or the Building caused by such removal. If Tenant fails to remove any such items (“Abandoned Items”) or repair such damage promptly after the expiration or earlier termination of the Lease, Landlord may, but need not, do so with no liability to Tenant, and Tenant shall pay Landlord the cost thereof upon demand. Tenant agrees to indemnify Landlord for any and all loss, cost, damage, liability or expense as incurred (including but not limited to reasonable attorneys’ fees and legal costs) arising out of or related to any claim, suit or judgment brought by or in favor of any person or persons for damage, loss or expense which arises out of, is occasioned by or is in any way attributable to the Abandoned Items. Notwithstanding the foregoing to the contrary, in the event that Landlord gives its consent, pursuant to the provisions of Section 9.01 of this Lease, to allow Tenant to make an Alteration in the Premises, Landlord agrees, upon Tenant’s written request, to notify Tenant in writing at the time of the giving of such consent whether Landlord will require Tenant, at Tenant’s cost, to remove such Alteration at the end of the Lease Term.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Base Rent Lessee shall pay Base Rent and other rent or charges, as the same may be adjusted from time to time, to Lessor in lawful money of the United States, without offset or deduction, on or before the day on which it is due under the terms of this Lease. Base Rent and all other rent and charges for any period during the term hereof which is for less than one full month shall be prorated based upon the actual number of days of the month involved. Payment of Base Rent and other charges shall be made to Lessor at its address stated herein or to such other persons or at such other addresses as Lessor may from time to time designate in writing to Lessee.
No Rent Abatement Tenant shall continue to pay all Rent due or accruing under this Lease during any Clean-up, and shall not be entitled to any reduction, offset or deferral of any Base Rent or Additional Rent due or accruing under this Lease during any such Clean-up.
