Description of the App and the Website
Description of the App and the Website Sample Clauses
Related to Description of the App and the Website
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
DESCRIPTION OF THE WORKS Employer’s objectives The scope of the request includes the recommended monthly preventative, quarterly and annual maintenance that needs to be conducted to ensure all areas of the airports are lit and compliant. It will include all the other adhoc request (labor rates) where required upon approval by the maintenance manager. The compliance will be based on the following: • Maintenance as per OEM • Organizational guidelines and codes of practice • OHS act 93 – Occupational Health and Safety • ISO 9001 – Quality management • ISO 14001 – Environmental Management • SANS 10142 – The wiring code • ICAO Annex 14 chapter 5. • ACSA Maintenance Procedure D060 024M This scope entails the maintenance and repair of LV systems and all lighting at Costal airports. In brief, maintenance involves servicing, repairs, and testing of lights and LV systems. This involves carrying out maintenance on electrical equipment such as LV DBs, electrical plant, wiring enclosures and luminaires and associated control systems, portable appliances and other specific electrical equipment, in order to minimize downtime, and ensure that the equipment performs at optimal levels and functions to specification at the specified areas. Servicing - performing routine preventive maintenance as prescribed by the original equipment manufacturer (OEM), ACSA’s planned maintenance routines, and applicable legal and design standards. Repairs – responding to breakdowns, callouts and restoring the equipment to safe working conditions on an as and when basis. Advisory – telephonically guiding airport electricians under emergency situations to ensure systems are safely shutdown or returned to service within stringent times. System Performance Test – Testing equipment performance against the OEM, ACSA, and statutory requirements for compliance and return to service purposes. Extent of the works The Contractor will be fully responsible for meeting all requirements in this document regarding the Works. For each piece of equipment, all work will be carried out to standards as required by the Original Equipment Manufacturer (OEM) as well as any applicable governing law and/or regulations. Where OEM standards differ from those required by this document the more stringent requirement shall apply. The Contractor will be fully responsible for obtaining (and keeping up to date with) said requirements. The proposed minimum scheduled maintenance activities can be found in annex H.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a two bedroom service apartment unit, intermediate lot bearing postal address of No. A-20-10, Xxxxxx A, Residensi Southkey Mozek, Persiaran Southkey Utama, Kota Xxxxxxxx, 00000 Xxxxx Xxxxx, Xxxxx. RESERVE PRICE: The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM486,000.00 (RINGGIT MALAYSIA FOUR HUNDRED AND EIGHTY SIX THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Xxxxxxx’s Order in favour of UOBM for CHOONG LIP PONG or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S CHUA & PARTNERS, of Suite 8-12A-6, Xxxxx 00X, Xxxxxx Xxxxxxx, Xx. 0, Xxxxx Xxxx Xxxxxx, 00000 Xxxxx Xxxxxx. (Ref No.: MHH/UOB/A924/22/ChoongLipPong, Tel No. 00-0000 0000 / 00-0000 0000, Fax No.: 00-0000 0000) solicitors for the Assignee herein or the undermentioned Auctioneer. EHSAN AUCTIONEERS SDN. BHD. (Co. No. 617309-U) DATO’ HAJI XXXXX XXXXX BIN X.X. XXXX (D.I.M.P) Xxxxx X-00-0X, Xxxxx 00, Xxxxx X, Xxxxx Xxxxxx II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 & 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: XXXXX/UOB0477/CP(2) Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx OR Unit Xx. 0.00, 0xx Xxxxx, Xxxxxx XXX, Xx. 0, Xxxxx Xxxx Xxxx Xxxxx, 80000 Johor Bahru, Johor. H/P EN JO: 012-742 1763 (Marketing) PERISYTIHARAN JUALAN DALAM PERKARA MENGENAI PERJANJIAN PINJAMAN XXX SURATIKATAN PENYERAHAN HAK KEDUA-DUANYA BERTARIKH 06HB SEPTEMBER, 2016 ANTARA UNITED OVERSEAS BANK (MALAYSIA) BHD [No. Pendaftaran: 199301017069/271809-K] PIHAK PEMEGANG SERAHHAK/BANK XXX XXXXXX LIP PONG (NO K/P.: 820721-01-5979) PIHAK PEMINJAM / PIHAK PENYERAHHAK Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Pinjaman xxx Suratikatan Penyerahan Hak Kedua-duanya bertarikh 06hb September, 2016 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah. AKAN MENJUAL HARTANAH YANG DIHURAIKAN DI BAWAH SECARA LELONGAN AWAM SECARA ATAS TALIAN PADA 11HB JANUARI 2023BERSAMAAN HARI RABU, JAM 3.00 PETANG, XX XXXXX WEB XXX.XXXXXXXXXXXXXXXX.XXX Bakal pembida boleh mengemukakan bida untuk hartanah dalam talian melalui xxx.xxxxxxxxxxxxxxxx.xxx (Untuk pembidaan dalam talian, xxxx daftar sekurang-kurangnya satu (1) hari bekerja sebelum hari lelong untuk tujuan pendaftaran & pengesahan) NOTA: Xxxxx-xxxxx pembeli adalah dinasihatkan agar membuat perkara-perkara yang berikut sebelum jualan lelong:-
Description of the transfer(s) The details of the transfer(s), and in particular the categories of personal data that are transferred and the purpose(s) for which they are transferred, are specified in Annex I.B. Docking clause
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Formation of the Agreement 2.1 The Agreement is binding upon Supplier after accepting the Purchase Order as evidenced by acknowledgement, supply of Goods and/or performance of Services. Versuni expressly rejects Supplier’s general conditions of sale.
Implementation of the Agreement Regulations of this Agreement relating to investments who investors of one Contracting Party realized before or after the entry into force of this Agreement, with what shall apply from the moment of its entry into force, provided that such investments conducted in accordance with the laws of that Party Contracting.
Publication of the Agreement Copies of this Agreement shall be made available to all members of the appropriate unit by posting the Agreement on the District’s website within thirty (30) working days after the Agreement is executed.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
Description of the Transfer The details of the transfer and of the personal data are specified in Annex B. The parties agree that Annex B may contain confidential business information which they will not disclose to third parties, except as required by law or in response to a competent regulatory or government agency, or as required under clause I(e). The parties may execute additional annexes to cover additional transfers, which will be submitted to the authority where required. Annex B may, in the alternative, be drafted to cover multiple transfers. ANNEX A
